| Party Dtls | Self / Adv Name | District | Current Status | Next Date of Hearing | Complaint Dispatched | Complaint Dispatched On | Dispatched Tracking Id | Complaint Dispatched Remarks | First-Hearing/Scrutinized Remarks | View Notice |
|---|---|---|---|---|---|---|---|---|---|---|
| HARERA THROUGH NEERAJ V/S SRIFLEX PROJECTS PRIVATE LIMITED |
Self | GURUGRAM | DISPOSED | NOT REQUIRED | Yes | 12-Nov-2024 | RERA-GRG-5637-2024 | DISPATCHED | RC condition non compliance |
| Notice Number | Remarks | Dispatching Date | Dispatch Id | View Notice |
|---|---|---|---|---|
| First Notice | DISPATCHED | 12-Nov-2024 | RERA-GRG-5637-2024 |
| Date of Hearing | Status | Proceedings of the day | Bench | Order | Order Uploaded On |
|---|---|---|---|---|---|
| 26-Dec-2024 | DISPOSED | Ar. Neeraj Gautam (Associate Architectural Executive) briefed the facts of the case. Sh. Manoj Tewari (AR) and Sh. Inderjeet Singh (CEO) appeared on behalf of the promoter and request to condone the delay. The AR of the promoter has submitted a reply dated 26.12.2024 wherein it is stated that the promoter had applied for respective applications with the concerned departments, however, there was undue delay at the respective departments which ended in the delay of approvals. It is stated that the application for EC was made on 17.01.2024 and the same was on hold since there was no Chairman in the department and no meeting was held. The application was resumed after reinstatement of Chairman. A request letter dated 27.04.2024 for inclusion in the agenda was submitted to SEAC and the project was taken up in the SEAC meeting dated 15.05.2024 and then SEIAA meeting dated 23.07.2024. The final environmental clearance was granted on 31.08.2024. It is further stated that the application for approval of service plans and estimates was made in the last week of April 2024 and on 21.05.2024 the file was recommended by Executive Engineer HSVP Gurugram. The file was further recommended from Chief Engineer HSVP Chandigarh to DTCP on 05.07.2024 and the final approval was granted on 16.09.2024. There was no deficiency or shortcomings in the file, hence, the delay was purely procedural internal delay in the department. However, it is not disputed that the promoter was granted conditional registration at its own accord and depositing of security amount in the form of demand draft in lieu of submission of the requisite clearances within the time specified in the conditional registration. It was clearly mentioned in the registration certificate that these DDs shall be forfeited in favour of Authority in case the conditions are not fulfilled by the promoter within the stipulated time period. In view of the above, the security amount submitted in lieu of timely submission of environmental clearance and approved service plans and estimates is hereby forfeited. The security amount submitted on account of the approved fire scheme already stands refunded as the same was obtained within the stipulated time. Since the compliance has now been made, although with a delay, the case is filed. Detailed order shall follow. | ASHOK SANGWAN | View Order | 02-Jan-2025 |
| 12-Dec-2024 | FIRST HEARING | Ar. Neeraj Gautam (Associate Architectural Executive) briefed the facts of the case. Sh. Manoj Tewari (AR) appeared on behalf of the promoter and requested to condone the delay and an extension of 15 days’ time to submit the detailed reply as the directors of the promoter company are not available till 15.12.2024. Considering the request of the authorized representative of the promoter, one last opportunity is granted to the promoter to submit a detailed reply with respect to the show cause notice dated 12.11.2024. The matter to come up on 26.12.2024. | ASHOK SANGWAN | View Order | 17-Dec-2024 |
| Date of Judgement | Party Details | Judgement Uploading Date | View Judgement |
|---|---|---|---|
| 26-Dec-2024 | HARERA THROUGH NEERAJ V/S SRIFLEX PROJECTS PRIVATE LIMITED |
--- | --- |
| Dak ID | Receiving Date | Submitted By | Remarks |
|---|---|---|---|
| 84407 | 26/12/2024 | SANJAY SAINI | SUBMISSION IN COMPLIANCE TO ORDER |
| 82293 | 12/11/2024 | HARERA THROUGH NEERAJ | NEW COMPLAINT |
| 83683 | 12/12/2024 | MANOJ TIWARI | REPLY TO SHOW-CAUSE NOTICE- 5637-2024. |
| 102346 | 18/11/2025 | INDERJEET SINGH | CLARIFICATION REGARDING THE SUBMISSION IN COMPLIANCE TO ORDER DATED 12.12.2024 ISSUED BY THE DEPARTMENT FOR PROJECT |
Web Information Manager
Shri Sunil Hooda,Secretary(Acting), HRERA
Mini Secretariat, New Office Block,
2nd & 3rd Floor ,Sector-1,
Panchkula,
Haryana- 134114,India
Email: hrerapkl[dash]hry[at]gov[dot]in
Telephone: +91 172-2584232,2585232
Website Designed and Developed By National Informatics Centre (NIC) and Owned by HRERA PANCHKULA & HRERA GURUGRAM Jointly
© 2018 Copyright. All Rights Reserved.